Terms & Conditions - Sumangali Infrashell

Welcome to Sumangali Infrashell. By accessing our website or engaging with our services, you agree to comply with and be bound by the following Terms & Conditions. Please read them carefully.

1. Acceptance of Terms
By using our website or services, you agree to these Terms & Conditions in full. If you do not agree, please refrain from using our services.

2. Services
Sumangali Infrashell provides construction-related services, including residential and commercial project execution, consultation, and related solutions. All services are subject to project-specific agreements, scope, and timelines.

3. User Responsibilities
By using our website or services, you agree:

To provide accurate and complete information
Not to use the website for any unlawful or prohibited activities
Not to attempt to disrupt or compromise website security

4. Project Agreements & Payments

All construction projects will be governed by a separate written agreement outlining scope, cost, and timelines
Payment terms, schedules, and milestones will be clearly defined in the agreement
Delays in payment may affect project timelines or lead to suspension of work

5. Intellectual Property
All content on this website, including text, images, logos, and designs, is the property of Sumangali Infrashell and is protected by applicable intellectual property laws. Unauthorized use or reproduction is strictly prohibited.

6. Limitation of Liability
While we strive to deliver high-quality services, Sumangali Infrashell shall not be held liable for:

Any indirect, incidental, or consequential damages
Delays caused by factors beyond our control (e.g., weather conditions, material shortages, regulatory approvals)

7. Website Usage

The content on this website is for general informational purposes only
We reserve the right to modify or discontinue any part of the website without notice
We do not guarantee that the website will always be error-free or uninterrupted

8. Third-Party Links
Our website may include links to external websites. We are not responsible for the content or practices of those third-party sites.

9. Termination
We reserve the right to restrict or terminate access to our website or services if there is a violation of these Terms & Conditions.

10. Governing Law
These Terms & Conditions shall be governed by and interpreted in accordance with the laws of India. Any disputes arising shall be subject to the jurisdiction of the courts in [Insert City, e.g., Chennai].

11. Changes to Terms
Sumangali Infrashell reserves the right to update or modify these Terms & Conditions at any time. Changes will be effective upon posting on this page.